20 I The Lovell Chronicle I March 1, 2012
Public notices
High Risk Rural Road ;ign bids
ADVERTISEMENT FOR BIDS
Notice is hereby given that the Big Horn County Commission will
receive sealed bids for the High Risk Rural Road Sign Project #PME-
011204. The work consists of furnishing all labor, materials, tools,
equipment, transportation, and services necessary for the placement
of approximately 850 Road Signs in various locations throughout Big
Horn County as per plans, drawings, specifications and job conditions
as called for in the Project Manual.
Bids will be received for High Risk Rural Road Sign Project at
the Office of the County Clerk, in the County Offices, 420 West C
Street, EO. Box 31, Basin, Wyoming 82410 until 2:00 EM. Local Time,
on March 15, 2012, at which time the bids will be publicly opened
and read aloud. All bids must be furnished on forms supplied in the
project manual. Sealed envelopes containing bids shall be clearly
marked with High Risk Rural Road Sign Project and shall show the
name and address of the Bidder. Bids which are not prepared and
filed in accordance with the Instructions to Bidders may be rejected.
The County reserves the right to reject any and all bids and the right
to waive irregularities in bids received.
Each bid must be accompanied by a bid bond with sufficient
surety, or a certified check or cashier's check, or bank draft on a
reputable bank, for not less than five percent (5%) of the total amount
of such bid, payable to, and to be forfeited to, the County of Big Horn
as liquidated damages if bidder fails to enter into contract within thirty
(30) days after award to him, or fails, at the time of executing the
agreement, to furnish a performance bond and a payment bond each in
the amount of one hundred percent (100%) of the bid. Facsimile (fax) or
other copies of bonds are not acceptable, nor are certified or cashier's
checks which have an expiration date of less than one year. NO BID
WILL BE CONSIDERED IF NOT ACCOMPANIED BY SUCH BOND,
CERTIFIED OR CASHIER'S CHECK OR BANK DRAFT, OR IF NOT
IN CONFORMANCE WITH THE PROVISIONS OF SECTION 15-1-
113, W.S. 1977. Completion date to be October 1, 2012.
A complete set of the Project Manual and Plans may be obtained
for a $75.00 fee at Pryor Mountain Engineering, P.O. Box 671, 708
Road 7 ½ Cowley Wyoming 82420. Bidders may contact William
Bridges, Pryor Mountain Engineering, at (307)548-9913 if there are
any questions or to view the project.
COUNTY OF BIG HORN, WYOMING
JEROLD S. EWEN, COMMISSION CHAIRMAN
Publish: February 23, March 1 & 8, 2012.
Bier Horn County transfer of funds
NOTICE OF HEARING (NOH #8, 2011-2012)
March 1, 2012
Notice is hereby given of a public hearing on a proposed transfer
of funds to the following budgets:
• $2,500.00 From South Airport Cash Reserve, 81-
4-551-980-000 to 81-4.501-310-000 South
Airport Equipment Maintenance
• 88,000.00 From Cash Reserve (County Funds) 10-
4-951-980-000 to 10-4-901-321-000 Burial
Service
• $35,270.70 From Cash Reserve (County Funds) to 10-
4.162-000-000 Fair Grounds Maintenance
The board of county commissioners will hold a heating at
10:45 a.m. on March 6, 2012, in the commissioners' chambers at the
courthouse in Basin, at which time any and all persons interested may
appear and be heard respecting such transfer of funds.
Dated this 6" day of March, 2012
Board of County Commissioners
Big Horn County, Wyoming
/s Jerold S. Ewen, ChairmL1i , ,,.,
/s Keith M. Grant, Menlbi ' :: ' ...... ..... ...... "
/s Thomas S. Hinman, Membgl .,,
Attest:
/s Dori Noyes, County Clerk, Clerk of the Board
Publish: March 1, 2012
Tax Deed notice of intent
NOTICE OF INTENT TO MAKE APPLICATION
FOR A TAX DEED
Notice is hereby given that on September 5, 2010, Karen Amend
purchased and assigned to Jacqueline A. Brown, Certificate of
Purchase Number 17424, Big Horn County, Wyoming, described as
drainage 100'x125' in N2 of E2 of Lot 45, 13 56 96.29 AC. Said property
is deeded in the names of Olson, Dustin T. and Tina Jelean. Said
property was subject to and assessed for taxation for the years 2009
and 2010. Time of redemption will expire June 4, 2012. Application
for tax deed will be made June 5, 2012. No special assessments
were noted. To redeem said property contact the Big Horn County
Treasurer in Basin, Wyoming,
Publish: February 16, 23, & March 1, 2012
Davis Road Bridge Repair final payment
NOTICE OF FINAL PAYMENT
The Big Horn County Commission, acting on behalf of Big Horn
County, Wyoming, has accepted all work as complete according to
the Contract Documents set forth in the written Agreement between
WILSON BROS. CONSTRUCTION, INC. and Big Horn County,
for the BIG HORN COUNTY DAVIS ROAD BRIDGE REPAIR, and
WILSON BROS. CONSTRUCTION, INC., Contractor, is entitled to
final payment.
Therefore, on the lff h day of APRIL, 2012, the 41st day after the
first publication of this notice, final payment of the full amount due
under the Agreement will be made. Nothing in this notice shall be
construed as relieving the Contractor and the Sureties on its bond
from any claim or claims for the work or labor done or materials or
supplies furnished in the execution of the Agreement.
BIG HORN COUNTY COMMISSION
JEROLD S. EWEN, CHAIRMAN
Publish: March 1 and 29, 2012
Byron Business Development Hearing
NOTICE OF PUBLIC HEARING
A Public Hearing will be held at the Town of Byron Town
Complex on March 8, 2012, at 6:00 p.m. to take public comment on
a proposed new business development to be located at 21 E. Main
Street, Byron, WY, Legal description 'East 73, Lot 3, Block 13, Original
Town of Byron'. The owner of the property is listed as Bair Mobile
Homes and Court, LLC. The owner has applied for a change of use for
the purpose of conducting a Mobile Home Sales and Repair business
which will include dismantling, recycling, repairing and disposing of
Mobile Homes. The building will be used to store building materials
for units being rebuilt, mobile home repair parts and materials for
resale to the general public, office and record keeping. This proposed
business will be located directly across the street from what Was the
previous Rocky Mountain School. Additional information regarding
this hearing can be picked up at the Byron Town Hall Office located in
the Byron Town Complex, Byron, WY.
Publish: March 1 & 8, 2012
Bi Horn County Liquor License applications
PUBLIC NOTICE
Notice is hereby given that on the 24 TM day of February, 2012, the
following applicants filed an application for a license, in the office of
the clerk of Big Horn County:
RETAIL LIOUOR LICENSES
• William & Joann Batts, DBA Hyattville Caf6 - Hyattville
• The Secrets of Shell, LLC, DBATrapper Creek Lodge Restaurant
- East of Shell
• Paint Rock Inn, LLC - Hyattville
• Steven IL Montanez, DBA Oasis Bar - Northwest of Lovell
• Hideout Adventures, Inc., DBAThe Hideout at Flitner Ranch-
East of Shell
• JR McLaughlan, Inc., DBA Dirty Annies Country Store- East of
Shell
• Meadowlark Lake Lodge, LLC, DBA Meadow Lake Lodge - East
of Ten Sleep
• Deer Haven Mountain Resort, LLC- East ofTen Sleep
LIMITED (CLUB) LIOUOR LICENCES
• Midway Golf Club - North of Basin
COUNTY RETAIL MALT.BEVERAGE EERMIT :, ,
,. A1Marfinl,rDBAAnflerInn,Shel[ i ;. ..... ,.,
• 01d Shell Lodge,LLC: Shell ...........................
• Snow§hoe Lodge, LLC - South East Of Shell "
• Wyoming High Country, LLC - Forest Service Road # 19, Lovell
protests, if any there be, against the issuance (transfer
or renewal) of the license will be heard at 1:30 PM on the
3 d day of April 2012, in the board of county commissioners
chambers, Basin, Wyoming.
Publish: March 1, 8, 15 & 22, 2012
Bi Horn County subdivision amendments
PUBLIC HEARING NOTICE
Pursuant to W.S. 18-5-201 through 208 and W.S. 18-5-301 through
318 Big Horn County Commissioners will hold a public meeting on
April 17, 2012 at 11:30 a.m. in the County Commissioners Chambers
in the County Courthouse in Basin, Wyoming. The hearing concerns
the adoption of the proposed amendments to the Big Horn County
Subdivision Regulations. The document may be viewed in the County
Clerk's Office and various libraries. Written comments may be sent to
Big Horn County Commissioners, P.O. Box 31, Basin, WY 82410. For
more information call the Planning Office at 307-568-2424.
Publish: March 1, 8, 15 & 22, 2012
Complaint for divnn:e
STATE OF WYOMING
COUNTY OF BIG HORN
) IN THE DISTRICT COURT
) ss. FIFTH JUDICIAL DISTRICT
) Civil Action Case No. 019512
ROSALINA ALVAREZ, plaintiff
vs.
ANTONIO ALVAREZ, defendant
NOTICE OF PUBLICATION
NOTICE TO ANTONIO ALVAREZ, Defendant/Respondent, ad-
dress unknown.
You are notified that a complaint for divorce; petition for child sup-
port and judgement for arrears; and petition to custody and support,
civil action No. 019512, has been filed in the Wyoming District Court
for the 5th Judicial District, whose address is 420 W. C St., Basin, Wyo-
ming 82410, seeking dissolution of your marriage to Rosalina Marie
Alvarez; custody and child support; and order custody and support in
his/her favor.
Unless you file an answer or otherwise respond to the complaint
or petition referenced above within 30 days following the last date of
publication of this notice, a default judgement will be taken against you
and a decree of divorce; order for child support and judgement for ar-
rears; and order granting custody and support will be granted.
Dated this 13th day of February, 2012.
By Clerk of Court VICKIE LARCHICK
By Mary J. Hillman, Deputy
Publish: February 23, March 1, 8, 15, 2012
Elk Creek Bridge Repair final payment
No'rICE OF FINAL PAYMENT
The Big Horn County Commission, acting on behalf of Big Horn
County, Wyoming, has accepted all work as complete according to
the Contract Documents set forth in the written Agreement between
PATRICK CONSTRUCTION, INC. and Big Horn County, for the
BIG HORN COUNTY ELK CREEK BRIDGE REPAIR, and PATRICK
CONSTRUCTION, INC., Contractor, is entitled to final payment.
Therefore, on the 10 th day of APRIL, 2012, the 41st day after the
first publication of this notice, final payment of the full amount due
under the Agreement will be made. Nothing in this notice shall be
construed as relieving the Contractor and the Sureties on its bond
from any claim or claims for the work or labor done or materials or
supplies furnished in the execution of the Agreement.
BIG HORN COUNTY COMMISSION
JEROLD S. EWEN, CHAIRMAN
Publish: March 1 and 29, 2012
Log C, ym Heating System Project bids
ADVERTISEMENT TO BID
Notice is hereby given that the Town of Cowley will receive sealed
bids for the LOG GYM HEATING SYSTEM PROJECT #PME-021203.
The work consists of furnishing all labor, materials, tools, equipment,
transportation, and services necessary for:
The supplying and installing of two Htg and cooling TRANE
packaged units. Heating capacity of each unit is 250 MBH input, and
10 ton cooling capacity including miscellaneous duct work, above
grade mounting and painted steel framing, as called for in the Plans
and Specifications for the LOG GYM HEATNG SYSTEM PROJECT.
Bids will be received at the Town Hall in the Town of Cowley, 20 South
Division, Cowley, Wyoming 82420 until 1 P.M. Local Time, on the 22 "0
day of March 2012, at which time the bids will be publicly opened
and read aloud. All bids must be furnished on forms supplied by the
Town of Cowley. Sealed envelopes containing bids shall:b .clearly
, marked L(G GYM, HEATING SYS'TtM,PRO. ,gnd shall show the
ii'aroe and address:0i'the Bidder on the outsids which are not
prepared and filed in accordance with the Instructions to Bidders may
be rejected. The Town of Cowley reserves the right to reject any and
all bids and the right to waive irregularities in bids received.
Each bid must be accompanied by a bid bond with sufficient
surety for not less than five percent (5%) of the total amount of such
bid, payable to and to be forfeited to, the Town of Cowley as liquidated
damages if bidder fails to enter into the contract within thirty (30)
days after award to bidder, or fails, at the time of executing the
agreement, to furnish a performance bond and a payment bond, each
in the amount of one hundred percent (100%) of the bid. Facsimile
(fax) or other copies of bonds are not acceptable. NO BID WILL BE
CONSIDERED IF NOT ACCOMPANIED BY SUCH BOND OR IF
NOT IN CONFORMANCE WITH THE PROVISIONS OF SECTION
15-1-113, W.S. 1977.
Project completion date will be June 30, 2012. A complete set
of Plans and Specifications may be obtained after March 1% 2012 for
a non-refundable fee of $25.00 from Pryor Mountain Engineering,
PO Box 671, 708 Road 7 ½, Cowley, Wyoming, 82420. For questions
regarding the project contact William Bridges, PE, at the following
telephone number: (307) 548-9913.
A pre-bid conference will be held at 1 PM on the 15 th of March
2012 at the Cowley Town Hall, Cowley, WY.
TOWN OF COWLEY
Joel Peterson, Mayor
Publish: March 1, 8 & 15, 2012
